(Download) "United States v. Utah Construction & Mining Co." by Supreme Court of the United States # eBook PDF Kindle ePub Free

January 17, 2021

eBook details

Title: United States v. Utah Construction & Mining Co.
Author : Supreme Court of the United States
Release Date : January 06, 1966
Genre: Law,Books,Professional & Technical,
Pages : * pages
Size : 83 KB

Description

The typical construction contract between the Government and a private contractor provides for an equitable adjustment of the contract price or an appropriate extension of time, or both, if the government orders permitted changes in the work or if the contractor encounters changed conditions differing materially from those ordinarily anticipated. Likewise, it is provided that the contract shall not be terminated nor the contractor charged with liquidated damages if he is delayed in completing the work by unforeseeable conditions beyond his control, including acts of the Government. See Armed Services Procurement Regulations (hereinafter ASPR), 32 CFR ?? 7.602-3 to 7.602-5; Atomic Energy Commission Procurement Regulations (hereinafter AECPR), 41 CFR